建设工程设计合
Construction Project Design Contract
项目名称：
Project Name
项目建设点：
Project Location
合编号：
Contract No
设计证书等级：
Grade of Design License
委托方：
Client
承接方：
Design Firm
签订日期：
Signed on
委托方（甲方）：
Client (Party A)
承接方（乙方）：
Design Firm (Party B)
甲方委托乙方承担XX项目（期）工程设计双方协商致签订合
Party A entrusts Party B to undertake the design for This Contract is made by the two parties after their mutual agreement
第条 合列文件签订
Article1 This Contract is made on the basis of the following documents
11中华民国合法中华民国建筑法建设工程勘察设计市场理规定
11 The Contract Law of the People’s Republic of Chin The building regulations of the People’s Republic of China and The developmental Law of the People’s Republic of China
12国家方关建设工程勘察设计理法规规章
12 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality
13建设工程相关批准文件
13 The approval documents that are required for this construction project
第二条 合工程设计项目名称点规模投资容标准
Article2 The name location size investment sum function design contents and standards
21工程项目名称：XX项目（期）
21 Project name
22工程项目点：
22 Project location
23工程项目规模：总建筑面积约 方米（中面积约 方米）高度 米
23 Project size The total floor area is approximately ㎡(of which the floor area of the underground area is ㎡) the total height is ｍ
24工程特征附注说明：商业办公综合楼
24 Project features & remarks A commercial cum office building complex
25工程项目投资总额：控制 亿元民币
25 Project investment in total Controlled Within million yuan RMB
26工程项目设计容标准：红线建筑结构机电总体设计（包括3000㎡防设计包括精装修设计园艺设计艺术泛光明等专业设计）施工图设计约70000㎡（包括五层七层SOHO区域）
26 Design requirements and scope of work The scope of work shall include master planning and building design that are located within the boundary line For building design it shall comprise of the architectural structural & ME work (including 3000㎡of Airraid shelter design but excluding other specialists’ design such as the Luxurious Interior Design Landscaping Design and Facade Flood Lighting Design) The total floor area during the working drawing stage is 70000㎡(excluding the SOHO Area which is starting from the fifth floor level to the seventh floor level)
第三条 甲方乙方提交关资料文件（见表）
Article3 Relevant documents which shall be issued by Party A to Party B
序号
SN
资料文件名称
Name of documents
份数
Copies
提交时间
Submission Date
备注
Remarks
1
政府批文
Government Approval Documents
1
全套
Full set
2
设计务书
Design Instructions
1
3
规划红线图
Plan of Property Line
1
4
水电气源落实情况说明
Design Information of Utilities (water electricity & gas supply etc)
1
5
规划设计求
Requirements from the Government
1
6
址勘探报告
Soil Investigation Report
1
7
原入桩资料
1
Design Information of As Built pilings
8
概念方案
Concept Design Information
1
第四条 乙方甲方交付设计文件（见表）
Article4 Design documents which shall be submitted by Party B to Party A (listed as follows)
序号
SN
设计文件名称
Design Documents
阶段
Phase
份数
Copies
提交时间
Submission Date
备注
Remarks
1
方案设计文件
Schematic Design Documents
方案
Schematic
10
30天
Within 30 days
2
初步设计文件
DD Documents
扩初
EPD
15
30天
Within 30 days
3
初步概算文件
Preliminary Estimate
扩初
EPD
2
7天
Within 7 days
4
施工图设计
Working Drawings
施工图
Construction Documents
15
桩位图扩初批准15天
The piling drawings will be submitted within 15 days after the DD Approval
余扩初批准60天
The rest of the drawings will be submitted within 60 days after the DD Approval
5
光盘文件
CD files
施工图
CD
1
定
To Be Decided
注：设计文件深度建筑工程设计文件编制深度规定（建设部2003年4月版）执行
Notes The design documents shall be prepared in compliance with the Regulations on detail requirements of design documents for construction project (issued by Ministry of construction dated in April 2003)
第五条 设计费支付方法
Article 5 Design fee and the mode of payment
51甲方应支付合项目设计费
（含乙方应缴纳税费政府规定应乙方交纳款项）
51 Party A shall pay the design fee of RMB yuan for this project to Party B (this fee shall include taxes and all other duties that should be paid by Party B as required by the government regulations)
52支付方法（见表）：
52 The payment method is (listed as the following)
序号
SN
阶段
Phase
金额（元）
Amount (yuan)
说明
Remarks
1
方案阶段
Schematic design
合签订30日
30 days after Contract is signed
2
扩初阶段
Design Development
扩初批准30日
30 days after DD Approval
3
施工图阶段
Construction Document
施工图提交审图30日
30 days after the CD Approval by the Authority
4
施工配合
Construction coordination
总包施工合签订30日
30 days after the main contractor has been awarded
施工配合58500000
元
工程开工季度分五期支付次支付7000000元
5 installment payment shall be made quarterly throughout the entire construction period Each installment amounting to 700000 yuan
5
竣工验收阶段
The Completion & Handing over stage
竣工验收
After the completion and handing over of the project
第六条 双方责
Article6 Responsibilities of both parties
61甲方责
61 Responsibilities of Party A
611甲方合第三条规定容规定时间乙方提交资料文件完整性正确性时限负责甲方提交述资料文件超规定期限15天乙方合第四条规定交付设计文件时间延超规定期限15天时乙方权重新确定提交设计文件时间
611 According to the contents stated in Article 3 of this Contract Party A shall submit materials and documents to Party B within the stipulated time as described and shall be responsible for the completeness correctness and validity of such materials and documents In the event that Party A has delayed the issuance of such materials and documents but not exceeding 15 days from the stipulated time Party B could consequently postpone the submittal of the design documents as stipulated in Article 4 of this Contract In case that Party A has delayed the issuance of materials and documents for more than 15 days exceeding the stipulated time limit Party B shall have the right to determine the new date for submitting the design documents
612甲方变更委托设计项目规模条件提交资料作重修改致造成乙方设计需返工时双方需行协商签订补充合重新明确关条款外甲方应乙方耗工作量乙方支付返工费
612 If Party A alters greatly the design project scale conditions which they have already entrusted to Party B or the materials provided by Party A is wrongincomplete or Party A makes major alterations to the approved design and the information given as a result of which has caused Party B to redo the design work or has generated unnecessary abortive works both parties shall enter into negotiation and to draw up a supplementary contract Party A shall compensate Party B for the additional work load in accordance t
o the new agreement
613合履行期间甲方单方提出解合乙方已开始设计工作甲方应根乙方已进行实际工作量支付设计费
613 Should Party A terminate the Contract during the contractual period Party A shall pay Party B according to the actual work done
614甲方收乙方付款通知书30天合第五条规定金额时间乙方支付设计费收付款通知书60天未支付逾期支付天应承担应支付金额千分逾期违约金逾期超30天时乙方权暂停履行阶段工作书面通知甲方甲方级设计文件部审批合项目停缓建甲方均应支付应付设计费
614 Party A shall pay the design fee to Party B within Thirty (30) days upon receiving the Notice of Payment from Party A according to the amount and the time stipulated in Article 5 In case that such payment is delayed for Sixty (60) days upon receiving the Notice of Payment then a penalty of 01 of the due amount of payment on a daily basis shall be paid by Party A In case that such payment is delayed for a period over 30 days Party B shall have the right to suspend their design work for the next phase and shall inform Party A in writing In case that the management of Party A does not approve the design documents or the construction of the project of this Contract is stopped or postponed Party A shall nevertheless pay the due design fee
615甲方求乙方合规定时间提前提交设计文件时甲方应支付赶工费
615 If Party A requests Party B to submit the design documents ahead of the stipulated time as mentioned in the Contract Party A shall make additional payment
for fast and immediate service
616方派现场工作员提供工作方便条件
616 Party A shall provide site office and all relevant office stationary for Party B’s personnel who are being sent to work site during the construction stage
617甲方应保护乙方设计版权未乙方意甲方乙方交付设计文件复制第三方转合外项目发生情况乙方权索赔
617 Party A shall protect the design copyright of Party B Without Party B’s consent Party A shall not duplicate of transfer to a third party or use the design documents for other projects If the abovementioned is happened Party B shall have the right to claim
62乙方责：
62 Responsibilities of Party B
621乙方合第四条规定容时间份数甲方交付设计文件
621 Party B shall submit to Party A the required design documents in right content time and copies according to the clause of Article 4
622乙方设计文件出现遗漏错误应施工前负责修改补充乙方设计错误造成工程质量事损失乙方负责采取补救措施外应免收损失部分设计费根损失程度甲方偿付赔偿金赔偿金额根乙方保险公司签订设计责保险合计算
622 Party B shall be responsible for correcting any omission or mistake in their design documents before the construction If the design mistake made by Party B has caused losses to Party A Party B shall not only be responsible for taking the remedial measures but also shall remit the design fee for the part of such losses and shall pay compensation to Party A according to the degree of such loss The amount of the compensation shall be determined by party B and his insurance company and to be in accordance to the professional indemnity insurance coverage
623乙方身原延误合第四条规定设计文件交付时间
延误天应减收该项目应收设计费千分
623 If it is Party B’s own fault to have delayed the submission of the design documents according to the stipulated time as described in Article 4 Party B shall deduct 01 of the due amount of the design fee on a daily basis for the delay period
624合生效乙方单方提出解合乙方应关规定赔偿甲方损失
624 After the Contract comes into forces if Party B proposes to terminate the Contract Party B shall compensate Party A’s losses according to the relevant regulations
625乙方交付设计文件应参加甲方相关职部门设计审查会议根审查结负责超出原定计划务书范围必调整补充负责甲方施工单位进行设计交底处理关设计问题参加竣工验收乙方应派相关员参加施工期间例会乙方应优化设计帮助业造价控制预算
625 After the design documents has been submitted Party B shall also attend the approval meetings held by Party A and the relevant competent authorities and shall be responsible for making the necessary adjustments revisions and supplements which does not exceed the scope of the documents of design requirements as originally defined based on the comments of such meetings Party B shall be responsible for explaining design details to Party A and the main contractor and shall be responsible for solving all the relevant design problems and to attend the handing over meeting Party B shall send the relevant personnel to participate in the regular site meetings suring the construction Party B should optimize the design to assist Party A in meeting the project budget
626乙方第三方扩散泄露转甲方提交产品图纸技术济资料发生情况甲方权乙方索赔
626 Party B is not allowed to disclose and transfer to a third party any product drawing technical and economic data etc which are provided by Party A In case that the abovementioned is happened Party A shall have the right to claim
627未甲方意乙方项目设计工作全部部分转包第三者
627 Party B is not allowed to subcontract the design work completely or partially to
any third party without the permission of Party A
第七条 约定
Article7 Other provisions
71甲方求乙方派专长期驻施工现场进行配合解决关问题时双方应行签订技术咨询服务合
71 When Party A requires Party B to send site personnel to the construction site for a long period the two parties shall negotiate for these additional work and sign a supplementary service Contract
72乙方合项目采国家方标准图甲方费关出版部门购买
72 Party A shall pay for all the relevant publications and standard collections of drawings issued by the state and local government which are needed by Party B for the purpose of designing the project
73合第四条规定乙方交付设计文件份数超合第四条规定份数乙方收工费
73 If Party B is requested to submit design documents of which the number of copies are more than those stipulated in Article 4 of this Contract Party A shall pay for those additional copies
74工程项目中建筑材料设备加工订货甲方需乙方设计员配合时需费甲方承担
74 If Party A requires Party B to provide personnel to assist them for procurement purposes such as the procurement of building material equipments etc the expenses needed shall be borne by Party A
75甲方委托乙方承担合容外工作服务行支付费
75 If Party A entrusts Party B to undertake those work and services which are beyond this Contract Party A shall pay additional fee
76抗拒素致合法履行时双方应时协商解决
76 When this Contract can not be executed because of the unforeseeable natural forces the two parities shall timely negotiate to solve the problem
77建设工程设计合履行程中发生纠纷双方应时协商解决协商成时双方意海市仲裁委员会仲裁
77 Both parties shall timely discuss each other for the settlement of any dispute arising during the execution of this Contract In case that such discussion fails both parties have agreed appealing to Shanghai Municipal A
rbitration Commission can be accepted
78甲方聘请 甲方顾问协助甲方进行设计理建筑设计咨询费甲方行支付
78 Party A has engaged to act as Party A’s consultants to assist Party A to provide the management and design consultation services The fee will be paid by Party A directly and separately
79合未事宜双方签订补充协议补充协议合具等效力
79 Supplementary agreement could be made between the two parties in case that any additional clause shall be added The supplementary agreement shall have the same effect and power as this Contract
710合式八份甲执四份乙执三份政府部门份
710 This Contract shall be made in 8 copies Party A shall hold 4 copies Party B shall hold 3 copies The government authority department shall hold one copy
711合中英书写矛盾应中文文准
711 This Contract is prepared in both Chinese and English languages in the event of conflicts in any of the provisions between the two versions provisions specified in the Chinese language version shall take precedence
712合双方签章30日报项目建设行政部门备案双方认必时项目工商行政理部门签证方履行完合规定义务合行终止
712 This Contract within 30 days after it has been signed and stamped by both parties shall be submitted to the local government authority for endorsement When it is considered necessary both parties could send this Contract to the local industrial and commercial administration departments for registration This Contract is to be terminated and expired itself after both parties have performed their duties as
stipulated in this Contract
713合甲乙双方盖章签字 年 月 日生效
（正文）
713 This Contract shall come into force beginning from the date when both parties have stamped it and signed it on
month year
委托方单位名称： 承接方单位名称：
（盖章） （盖章）
Party A Party B
(Stamp) (Stamp)
单位址： 单位址：
Address Address
邮政编码： 邮政编码：
Post Code Post Code
电 话： 电 话：
Tel Tel
电 传： 电 传：
Fax Fax
开户银行： 开户银行：
Name of bank Name of bank
银行账号： 银行账号：
Bank account Bank account
签订合代表（签字）： 签订合代表（签字）：
Contract Signing Representative Contract Signing Representative
合 年 月 日签海
This Contract is signed in Shanghai on (date) (month) (year)
法定代表： 法定代表：
Legal Representative Legal Representative
市勘察设计市场理部门意见： 市勘察设计市场理部门意见：
（盖章） （盖章）
备案日期： 签证日期：
年 月 日 年 月 日
文档香网(httpswwwxiangdangnet)户传
《香当网》用户分享的内容，不代表《香当网》观点或立场，请自行判断内容的真实性和可靠性！
该内容是文档的文本内容，更好的格式请下载文档
建设工程设计合
Construction Project Design Contract
项目名称：
Project Name
项目建设点：
Project Location
合编号：
Contract No
设计证书等级：
Grade of Design License
委托方：
Client
承接方：
Design Firm
签订日期：
Signed on
委托方（甲方）：
Client (Party A)
承接方（乙方）：
Design Firm (Party B)
甲方委托乙方承担XX项目（期）工程设计双方协商致签订合
Party A entrusts Party B to undertake the design for This Contract is made by the two parties after their mutual agreement
第条 合列文件签订
Article1 This Contract is made on the basis of the following documents
11中华民国合法中华民国建筑法建设工程勘察设计市场理规定
11 The Contract Law of the People’s Republic of Chin The building regulations of the People’s Republic of China and The developmental Law of the People’s Republic of China
12国家方关建设工程勘察设计理法规规章
12 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality
13建设工程相关批准文件
13 The approval documents that are required for this construction project
第二条 合工程设计项目名称点规模投资容标准
Article2 The name location size investment sum function design contents and standards
21工程项目名称：XX项目（期）
21 Project name
22工程项目点：
22 Project location
23工程项目规模：总建筑面积约 方米（中面积约 方米）高度 米
23 Project size The total floor area is approximately ㎡(of which the floor area of the underground area is ㎡) the total height is ｍ
24工程特征附注说明：商业办公综合楼
24 Project features & remarks A commercial cum office building complex
25工程项目投资总额：控制 亿元民币
25 Project investment in total Controlled Within million yuan RMB
26工程项目设计容标准：红线建筑结构机电总体设计（包括3000㎡防设计包括精装修设计园艺设计艺术泛光明等专业设计）施工图设计约70000㎡（包括五层七层SOHO区域）
26 Design requirements and scope of work The scope of work shall include master planning and building design that are located within the boundary line For building design it shall comprise of the architectural structural & ME work (including 3000㎡of Airraid shelter design but excluding other specialists’ design such as the Luxurious Interior Design Landscaping Design and Facade Flood Lighting Design) The total floor area during the working drawing stage is 70000㎡(excluding the SOHO Area which is starting from the fifth floor level to the seventh floor level)
第三条 甲方乙方提交关资料文件（见表）
Article3 Relevant documents which shall be issued by Party A to Party B
序号
SN
资料文件名称
Name of documents
份数
Copies
提交时间
Submission Date
备注
Remarks
1
政府批文
Government Approval Documents
1
全套
Full set
2
设计务书
Design Instructions
1
3
规划红线图
Plan of Property Line
1
4
水电气源落实情况说明
Design Information of Utilities (water electricity & gas supply etc)
1
5
规划设计求
Requirements from the Government
1
6
址勘探报告
Soil Investigation Report
1
7
原入桩资料
1
Design Information of As Built pilings
8
概念方案
Concept Design Information
1
第四条 乙方甲方交付设计文件（见表）
Article4 Design documents which shall be submitted by Party B to Party A (listed as follows)
序号
SN
设计文件名称
Design Documents
阶段
Phase
份数
Copies
提交时间
Submission Date
备注
Remarks
1
方案设计文件
Schematic Design Documents
方案
Schematic
10
30天
Within 30 days
2
初步设计文件
DD Documents
扩初
EPD
15
30天
Within 30 days
3
初步概算文件
Preliminary Estimate
扩初
EPD
2
7天
Within 7 days
4
施工图设计
Working Drawings
施工图
Construction Documents
15
桩位图扩初批准15天
The piling drawings will be submitted within 15 days after the DD Approval
余扩初批准60天
The rest of the drawings will be submitted within 60 days after the DD Approval
5
光盘文件
CD files
施工图
CD
1
定
To Be Decided
注：设计文件深度建筑工程设计文件编制深度规定（建设部2003年4月版）执行
Notes The design documents shall be prepared in compliance with the Regulations on detail requirements of design documents for construction project (issued by Ministry of construction dated in April 2003)
第五条 设计费支付方法
Article 5 Design fee and the mode of payment
51甲方应支付合项目设计费
（含乙方应缴纳税费政府规定应乙方交纳款项）
51 Party A shall pay the design fee of RMB yuan for this project to Party B (this fee shall include taxes and all other duties that should be paid by Party B as required by the government regulations)
52支付方法（见表）：
52 The payment method is (listed as the following)
序号
SN
阶段
Phase
金额（元）
Amount (yuan)
说明
Remarks
1
方案阶段
Schematic design
合签订30日
30 days after Contract is signed
2
扩初阶段
Design Development
扩初批准30日
30 days after DD Approval
3
施工图阶段
Construction Document
施工图提交审图30日
30 days after the CD Approval by the Authority
4
施工配合
Construction coordination
总包施工合签订30日
30 days after the main contractor has been awarded
施工配合58500000
元
工程开工季度分五期支付次支付7000000元
5 installment payment shall be made quarterly throughout the entire construction period Each installment amounting to 700000 yuan
5
竣工验收阶段
The Completion & Handing over stage
竣工验收
After the completion and handing over of the project
第六条 双方责
Article6 Responsibilities of both parties
61甲方责
61 Responsibilities of Party A
611甲方合第三条规定容规定时间乙方提交资料文件完整性正确性时限负责甲方提交述资料文件超规定期限15天乙方合第四条规定交付设计文件时间延超规定期限15天时乙方权重新确定提交设计文件时间
611 According to the contents stated in Article 3 of this Contract Party A shall submit materials and documents to Party B within the stipulated time as described and shall be responsible for the completeness correctness and validity of such materials and documents In the event that Party A has delayed the issuance of such materials and documents but not exceeding 15 days from the stipulated time Party B could consequently postpone the submittal of the design documents as stipulated in Article 4 of this Contract In case that Party A has delayed the issuance of materials and documents for more than 15 days exceeding the stipulated time limit Party B shall have the right to determine the new date for submitting the design documents
612甲方变更委托设计项目规模条件提交资料作重修改致造成乙方设计需返工时双方需行协商签订补充合重新明确关条款外甲方应乙方耗工作量乙方支付返工费
612 If Party A alters greatly the design project scale conditions which they have already entrusted to Party B or the materials provided by Party A is wrongincomplete or Party A makes major alterations to the approved design and the information given as a result of which has caused Party B to redo the design work or has generated unnecessary abortive works both parties shall enter into negotiation and to draw up a supplementary contract Party A shall compensate Party B for the additional work load in accordance t
o the new agreement
613合履行期间甲方单方提出解合乙方已开始设计工作甲方应根乙方已进行实际工作量支付设计费
613 Should Party A terminate the Contract during the contractual period Party A shall pay Party B according to the actual work done
614甲方收乙方付款通知书30天合第五条规定金额时间乙方支付设计费收付款通知书60天未支付逾期支付天应承担应支付金额千分逾期违约金逾期超30天时乙方权暂停履行阶段工作书面通知甲方甲方级设计文件部审批合项目停缓建甲方均应支付应付设计费
614 Party A shall pay the design fee to Party B within Thirty (30) days upon receiving the Notice of Payment from Party A according to the amount and the time stipulated in Article 5 In case that such payment is delayed for Sixty (60) days upon receiving the Notice of Payment then a penalty of 01 of the due amount of payment on a daily basis shall be paid by Party A In case that such payment is delayed for a period over 30 days Party B shall have the right to suspend their design work for the next phase and shall inform Party A in writing In case that the management of Party A does not approve the design documents or the construction of the project of this Contract is stopped or postponed Party A shall nevertheless pay the due design fee
615甲方求乙方合规定时间提前提交设计文件时甲方应支付赶工费
615 If Party A requests Party B to submit the design documents ahead of the stipulated time as mentioned in the Contract Party A shall make additional payment
for fast and immediate service
616方派现场工作员提供工作方便条件
616 Party A shall provide site office and all relevant office stationary for Party B’s personnel who are being sent to work site during the construction stage
617甲方应保护乙方设计版权未乙方意甲方乙方交付设计文件复制第三方转合外项目发生情况乙方权索赔
617 Party A shall protect the design copyright of Party B Without Party B’s consent Party A shall not duplicate of transfer to a third party or use the design documents for other projects If the abovementioned is happened Party B shall have the right to claim
62乙方责：
62 Responsibilities of Party B
621乙方合第四条规定容时间份数甲方交付设计文件
621 Party B shall submit to Party A the required design documents in right content time and copies according to the clause of Article 4
622乙方设计文件出现遗漏错误应施工前负责修改补充乙方设计错误造成工程质量事损失乙方负责采取补救措施外应免收损失部分设计费根损失程度甲方偿付赔偿金赔偿金额根乙方保险公司签订设计责保险合计算
622 Party B shall be responsible for correcting any omission or mistake in their design documents before the construction If the design mistake made by Party B has caused losses to Party A Party B shall not only be responsible for taking the remedial measures but also shall remit the design fee for the part of such losses and shall pay compensation to Party A according to the degree of such loss The amount of the compensation shall be determined by party B and his insurance company and to be in accordance to the professional indemnity insurance coverage
623乙方身原延误合第四条规定设计文件交付时间
延误天应减收该项目应收设计费千分
623 If it is Party B’s own fault to have delayed the submission of the design documents according to the stipulated time as described in Article 4 Party B shall deduct 01 of the due amount of the design fee on a daily basis for the delay period
624合生效乙方单方提出解合乙方应关规定赔偿甲方损失
624 After the Contract comes into forces if Party B proposes to terminate the Contract Party B shall compensate Party A’s losses according to the relevant regulations
625乙方交付设计文件应参加甲方相关职部门设计审查会议根审查结负责超出原定计划务书范围必调整补充负责甲方施工单位进行设计交底处理关设计问题参加竣工验收乙方应派相关员参加施工期间例会乙方应优化设计帮助业造价控制预算
625 After the design documents has been submitted Party B shall also attend the approval meetings held by Party A and the relevant competent authorities and shall be responsible for making the necessary adjustments revisions and supplements which does not exceed the scope of the documents of design requirements as originally defined based on the comments of such meetings Party B shall be responsible for explaining design details to Party A and the main contractor and shall be responsible for solving all the relevant design problems and to attend the handing over meeting Party B shall send the relevant personnel to participate in the regular site meetings suring the construction Party B should optimize the design to assist Party A in meeting the project budget
626乙方第三方扩散泄露转甲方提交产品图纸技术济资料发生情况甲方权乙方索赔
626 Party B is not allowed to disclose and transfer to a third party any product drawing technical and economic data etc which are provided by Party A In case that the abovementioned is happened Party A shall have the right to claim
627未甲方意乙方项目设计工作全部部分转包第三者
627 Party B is not allowed to subcontract the design work completely or partially to
any third party without the permission of Party A
第七条 约定
Article7 Other provisions
71甲方求乙方派专长期驻施工现场进行配合解决关问题时双方应行签订技术咨询服务合
71 When Party A requires Party B to send site personnel to the construction site for a long period the two parties shall negotiate for these additional work and sign a supplementary service Contract
72乙方合项目采国家方标准图甲方费关出版部门购买
72 Party A shall pay for all the relevant publications and standard collections of drawings issued by the state and local government which are needed by Party B for the purpose of designing the project
73合第四条规定乙方交付设计文件份数超合第四条规定份数乙方收工费
73 If Party B is requested to submit design documents of which the number of copies are more than those stipulated in Article 4 of this Contract Party A shall pay for those additional copies
74工程项目中建筑材料设备加工订货甲方需乙方设计员配合时需费甲方承担
74 If Party A requires Party B to provide personnel to assist them for procurement purposes such as the procurement of building material equipments etc the expenses needed shall be borne by Party A
75甲方委托乙方承担合容外工作服务行支付费
75 If Party A entrusts Party B to undertake those work and services which are beyond this Contract Party A shall pay additional fee
76抗拒素致合法履行时双方应时协商解决
76 When this Contract can not be executed because of the unforeseeable natural forces the two parities shall timely negotiate to solve the problem
77建设工程设计合履行程中发生纠纷双方应时协商解决协商成时双方意海市仲裁委员会仲裁
77 Both parties shall timely discuss each other for the settlement of any dispute arising during the execution of this Contract In case that such discussion fails both parties have agreed appealing to Shanghai Municipal A
rbitration Commission can be accepted
78甲方聘请 甲方顾问协助甲方进行设计理建筑设计咨询费甲方行支付
78 Party A has engaged to act as Party A’s consultants to assist Party A to provide the management and design consultation services The fee will be paid by Party A directly and separately
79合未事宜双方签订补充协议补充协议合具等效力
79 Supplementary agreement could be made between the two parties in case that any additional clause shall be added The supplementary agreement shall have the same effect and power as this Contract
710合式八份甲执四份乙执三份政府部门份
710 This Contract shall be made in 8 copies Party A shall hold 4 copies Party B shall hold 3 copies The government authority department shall hold one copy
711合中英书写矛盾应中文文准
711 This Contract is prepared in both Chinese and English languages in the event of conflicts in any of the provisions between the two versions provisions specified in the Chinese language version shall take precedence
712合双方签章30日报项目建设行政部门备案双方认必时项目工商行政理部门签证方履行完合规定义务合行终止
712 This Contract within 30 days after it has been signed and stamped by both parties shall be submitted to the local government authority for endorsement When it is considered necessary both parties could send this Contract to the local industrial and commercial administration departments for registration This Contract is to be terminated and expired itself after both parties have performed their duties as
stipulated in this Contract
713合甲乙双方盖章签字 年 月 日生效
（正文）
713 This Contract shall come into force beginning from the date when both parties have stamped it and signed it on
month year
委托方单位名称： 承接方单位名称：
（盖章） （盖章）
Party A Party B
(Stamp) (Stamp)
单位址： 单位址：
Address Address
邮政编码： 邮政编码：
Post Code Post Code
电 话： 电 话：
Tel Tel
电 传： 电 传：
Fax Fax
开户银行： 开户银行：
Name of bank Name of bank
银行账号： 银行账号：
Bank account Bank account
签订合代表（签字）： 签订合代表（签字）：
Contract Signing Representative Contract Signing Representative
合 年 月 日签海
This Contract is signed in Shanghai on (date) (month) (year)
法定代表： 法定代表：
Legal Representative Legal Representative
市勘察设计市场理部门意见： 市勘察设计市场理部门意见：
（盖章） （盖章）
备案日期： 签证日期：
年 月 日 年 月 日
文档香网(httpswwwxiangdangnet)户传
《香当网》用户分享的内容，不代表《香当网》观点或立场，请自行判断内容的真实性和可靠性！
该内容是文档的文本内容，更好的格式请下载文档