建设工程设计合（二）
Engineering Service Contract (Ⅱ)
（专业建设工程设计合）
(Professional Engineering Service Contract For Construction Project)
工 程 名 称：
Name of the project
工 程 点：
Location of the project
合 编 号：
（设计编填）
Contract No
(Filled in by the Designer)
设计证书等级：
Level of the design certificate
发 包 ：
Employer
设 计 ：
Designer
签 定 日 期：
Date of contract
监制
江 苏 省 建 设 厅
江苏省工商行政理局
Supervised by Jiangsu Provincial Department of Construction
Jiangsu Provincial Administration for Industry and Commerce
发包
Employer (Party A)
设计
Designer (Party B)
发包委托设计承担 工程设计工程点 双方协商致签订合执行
The Employer entrust the Designer to undertake the engineering design of *** and the location for the project is within the plant of After friendly consultation the Parties hereby sign this Contract as follows：
第条 合签订
Article 1 Basis for the conclusion of this Contract
11中华民国合法中华民国建筑法 建设工程勘察设计市场理规定
11 The Contract Law of the People’s Republic of China The Construction Law of the People’s Republic of China Regulations on the Administration of the Market for Survey and Design of Engineering Construction
12 国家方关建设工程勘察设计理法规规章
12 National and local rules and regulations on the administration of the market for survey and design of engineering construction
13建设工程批准文件
1．3 Approval documents of the engineering construction
第二条 设计
Article 2 Basis for design of the engineering construction
21发包设计委托书设计中标文件
21 Letter of Authority or documents on letter of acceptance provided by the Employer to the Designer
22发包提交基础资料
22 Basic materials submitted by the Employer
23设计采技术标准：
国家方现行技术标准规范
23 The main technological standards adopted by the Designer are as follows
Current national and local technological standards rules and regulations
第三条 合文件优先次序
Article 3 Priority of the contractual documents
Current national and local technological standards rules and regulations
构成合文件视互相说明果合文件存歧义致根优先次序判断：
The several documents forming the Contract are to be taken as mutually explanatory of one another but in case of ambiguities or discrepancies the priority of the documents forming the contract shall be as follows
31合书
31 The Contract
32中标函（文件）
32 The Letter of Acceptance (documents)
33发包求委托书
33 Requirements of the Employer and letter of authority
34投标书
34 The Tender
第四条 合项目名称规模阶段投资设计容（根行业特点填写）
Article 4 Name size stages investment and content of design (which may be filled in according to the characteristics of the industry)
名称：
Name
规模：
Size
阶段：
Stage
投资：约 万美元
Investment About dollars
设计容工作范围：
Design content and work scope：
第五条 发包设计提交关资料文件时间
Article 5 Materials and documents delivered by the Employer to the Designer and time for delivery of materials and documents
1级部门批复文件(合生效)
1Official reply document by higher authority(after effectiveness of contract)
2设计开始前应提供关技术规格资料(合生效)
2The Employer should supply related technological specification documents before starting to design
3部门方案设计审批意见（施工图开始前提供）
3 Official reply of the power supply department on consent of the power supply(supply before construction drawing)
第六条 设计发包交付设计文件份数点时间
Article 6 Delivery of design documents by the Designer to the contract issuing party and copies location and time for the delivery
第七条 费
Article 7 Charges
7 1 双方商定合设计费 万元收费计算方法国家方关规定执行国家方没规定双方商定
71 The Parties agree that charges for the design hereunder shall be The basis for charges and the method of computing shall be in accordance with relevant national
and local provisions Where there are no relevant national and local provisions it shall be discussed and determined by the Parties
7 2 果述费估算设计费双方初步设计审批批准初步设计概算核算设计费工程建设期间遇概算调整设计费应作相应调整
72 If the design charges mentioned above are appraised prices both parties will compute design charges based on the approved rough estimate of preliminary design after preliminary design approval If there is rough estimate adjustment in period of engineering construction the design price will be adjusted accordingly
第八条 支付方式
Article 8 Terms of payment
81 合生效三天发包支付设计费总额30计 万元作定金（合结算时定金抵作设计费）
81 Within three days upon the effectiveness of this contract the Employer shall pay the Designer 30 of contract price namely RMB Yuan as the down payment( The down payment shall be counted as the charges for design upon settlement of the contract)
82设计提交 方案 设计文件三天发包支付设计费总额20计 万元设计提交 施工图 设计文件三天发包支付设计费总额45计 万元工程完工结清设计费留尾款
82 Within three days upon the submission of schematic design documents by the Designer the Employer will pay 20 of contract price namely RMB Yuan Within three days upon the submission of construction drawings by the Designer the Employer will pay 45 of contract price namely RMB Yuan After completion of the project the Employer will pay the rest RMB ** *Yuan without any remainder
83 双方委托银行代付代收关费
83 The Parties shall entrust bank to collect and pay for relevant charges
第九条 双方责
Article 9 Responsibilities of the Parties
91 发包责
91 Responsibilities of the Employer
911发包合第五条规定容规定时间设计提交基础资料文件完整性正确性时限负责发包求设计违反国家关标准进行设计
发包提交述资料文件超规定期限15天设计合第六条规定交付设计文件时间延发包交付述资料文件超规定期限15天时设计权重新确定提交设计文件时间
911 The Employer shall submit to Designer basic materials and documents within specified period as provided in Article 5 of this contract and shall be responsible for the completeness accuracy and time limit of the materials and documents The Employer shall not require the Designer to conduct design in violation of relevant
national standards
In case there is a delay of less than 15 days exceeding the specified time limit for the delivery of the above materials and documents by the Employer the time limit for the Designer to deliver design documents shall be extended accordingly in case there is a delay of more than 15 days exceeding the specified time limit for the delivery of the above materials and documents by the Employer the Designer shall have the right to redetermine the time for delivery of the design documents
912 发包变更委托设计项目规模条件提交资料错误提交资料作较修改设计周期变化致造成设计设计返工工作量加时双方行协商签订补充协议（订合）重新明确关条款外发包应设计耗工作量设计支付返工费
未签订合前发包已意设计发包做项设计工作发包应支付相应设计费
912 In case of the Designer’s rework on the design resulted for changes of the engineering size and conditions of the design by the Employer or mistakes of the materials submitted or major revision on the submitted materials the Parties shall conclude supplementary agreement separately (or conclude additional agreement) and redefine relevant terms and conditions and the Employer should pay charges for rework to the Designer according to the workload
The Employer has agreed before the conclusion of the contract that it will pay charges of design to the Designer for all the design works conducted by the Designer
913 合履行期间发包求终止解合设计未开始设计工作退发包已付定金已开始设计工作发包应根设计已进行实际工作量足半时该阶段设计费半支付超半时该阶段设计费全部支付
913 During the performance of the contract if the Employer requires to terminate or cancel the contract before the Designer starts the design work the Designer will not return the down payment already paid by the Employer if the Designer has started the design work the Employer shall pay for the actual workload already done by the Designer When the actual workload of the design is less than half of the work at the stage the Employer shall pay half of the payment for the design work at the stage When the actual workload of the design is more than half of the work at the stage the Employer shall pay all the payment for the design work at the stage
914发包必须合规定支付定金收定金作设计开工标志未收定金设计权推迟设计工作开工时间交付文件时间延
914 The Employer should pay down payment as provided by the contract and receipt of down payment will be the symbol for the commencement of the design work by the Designer The Designer shall have the right to put off the commencement date of the design work if it has not received the down payment and the time for delivery shall be extended accordingly
915发包应合规定金额日期设计支付设计费逾期支付天应承担支付金额千分二逾期违约金设计提交设计文件时间延逾期超30天时设计权暂停履行阶段工作书面通知发包发包级设计审批部门设计文件审批合项目停缓建 发包均应支付应付设计费
915 The Employer should pay charges for design to the Designer at the amount and date provided in this Contract For each day of overdue payment 2‰ of the overdue payment shall be paid as damages for overdue payment and the time for delivery by the Designer shall be extended accordingly Where the delay of payment has exceeded 30 days the Designer shall have the right to suspend the performance of the work at the next stage and give written notice to the Employer In case the higher authority or competent department of design approval would not approve the design documents or the engineering construction of this contract is suspended or stopped the Employer should pay the payable charges for design
916发包求设计合规定时间提前交付设计文件时须征设计意严重背离合理设计周期发包应支付赶工费
916 If the Employer requires the Designer to deliver the design documents in advance it should get the prior consent of the Designer without serious deviation from the reasonable design circle and the Employer shall pay the crush cost
917发包应设计派驻现场工作员提供工作生活交通等方面便利条件必劳动保护装备
917 The Employer should offer conveniences in aspects of working living and traffic and necessary laborprotection equipments
918设计文件中选国家标准图部标准图方标准图发包负责解决
918 The Employer shall be responsible for the national standard drawing ministerial standard drawing and local standard drawings
919承担项目外国专家设计办公室工作接费（包括传真电话复印办公等费）
919 The Employer shall bear the expenses for receiving foreign expert in charge of the engineering to the Designer’s office (including expenses on fax telephone and office affairs)
92 设计责
92 Designer’s responsibilities
921 设计应国家规定合约定技术规范标准进行设计合第六条规定容时间份数发包交付设计文件（出现911912914915规定关交付设计文件延情况外）提交设计文件质量负责
921 The Designer should carry out design work in accordance with technological rules and standards provided in this contract or the state and deliver design documents as the content time and copies specified in Article 6 of this Contract (except for the circumstances provided in Art 911 912 914 915 under which the delivery of design documents may be extended) and shall be responsible for the quality of the design documents
922 设计合理年限体结构50年（砖混框架结构）
922 The design life of the engineering construction shall be main structure fifty years
923负责外商设计资料进行审查负责该合项目设计联络工作
923 The Designer shall be responsible for the scrutiny on the foreign investor’s design material and contact on the design of the engineering
924 设计设计文件出现遗漏错误负责修改补充设计设计错误造成工程质量事损失设计负责采取补救措施外应免收损失部分设计费根损失程度发包支付赔偿金赔偿金数额受损部分设计费相等
924 The Designer shall be responsible for the revision or supplement to the mistakes or omission of the design documents If any engineering quality accidents happen because of the Designer’s fault the Designer should be responsible for taking remedial measures as well as reduce the design charges on the affected part of the design work and compensate the Employer according to the degree of loss The amount of the damages for compensation is no more than the design price of the actual loss
925 设计原延误设计文件交付时间延误天应减收该项目应收设计费千分二
925 If the delivery of design documents are delayed for the Designer’s reason each day overdue will resulted in the reduction of 2‰ of the design charges for the engineering
926 合生效设计求终止解合设计应双倍返发包已支付定金
926 After the contract enters into force the Designer may require termination or cancellation of the contract and the Designer should return the down payment in double
927 设计交付设计文件规定参加关级设计审查根审查结负责超出原定范围容做必调查补充设计合规定时限交付设计文件年项目开始施工负责发包施工单位进行设计交底处理关设计问题参加竣工验收年项目尚未开始施工
设计负责述工作需工作量发包适收取咨询服务费收费额双方商定
927 Upon delivery of the design documents the Designer shall participate in the inspection on the design by the relevant higher authority as provide and shall be responsible for necessary adjustment and supplements to the content within the original scope of the design according to the inspection conclusion The Designer shall start the construction within one year upon delivery of the design documents within the specified time limit and shall be responsible for the technological disclosure to the Employer and construction unit handling with relevant matters on design and participation in the acceptance upon completion of the engineering construction In case the engineering construction has not started within one year the Designer shall still be responsible for the above work and may collect reasonable service fee for consultancy from the Employer according to the needed workload The amount of the service fee shall be discussed and determined by the Parties
第十条 保密
Article 10 Confidentiality
双方均应保护方知识产权未方意方均方资料文件擅修改复制第三转合项目外项目发生情况泄密方承担切引起果承担赔偿责
Both Parties shall protect each other’s intellectual property rights Without prior consent neither party shall revise copy or transfer to a third party or use for the project other than the project of this Contract any materials and documents of the other party Under such circumstances the disclosing party shall be responsible for all the any consequence it resulted and shall bear the relevant compensation
第十条 仲裁
Article 11 Arbitration
建设工程设计合发生争议发包设计应时协商解决建设行政部门调解调解成时双方事意 仲裁委员会仲裁双方事未合中约定仲裁机构事未达成仲裁书面协议民法院起诉
If any disputes arises in connection with this Engineering Service Contract it shall be settle by friendly consultation of the Parties or be submitted to the competent local construction administration department for mediation Where the dispute can not be settled by mediation it shall be submitted to the Arbitration Committee for settlement Where the Parties have not agreed on the arbitration organization in the Contract nor conclude arbitration agreement in written form the dispute will be brought to the People’s Court
第十二条 合生效
Article 12 Contract effective and miscellaneous
121 发包求设计派专长期驻施工现场进行配合解决关问题时双方应行签定技术咨询服务合
121 As per the request of the Employer for dispatch of personnel to stay on the Construction site so as to coordinate and solve relevant issues the individual technical consultant service contract shall be signed by both parties
122 设计合项目服务施工安装结束止
122 Service provided by the Designer for the Project in this Contract will be concluded until the completion of construction and installation
123工程项目中设计指定建筑材料设备生产厂供货商发包需设计配合建筑材料设备加工订货时需费发包承担
123 In the projects of the Contract Designer shall not appoint manufacturers or Designers of construction materials and equipments Where there is a necessity that Designer shall cooperate with Employer in ordering the process of construction materials and equipments the relevant fee shall be paid by Employer
124 发包委托设计配合引进项目设计务询价外谈判国外技术考察直建成投产阶段应吸收承担关设计务设计员参加出国费制服费外费发包支付
124 The Employer entrusted the Designer to cooperate with the engineering work of imported project and design personnel undertaking relevant design assignment shall be included in all stages from enquiry business negotiation domestic and overseas technical inspection until the production period The fee for overseas business trip and other relevant fee will be paid by Employer except the fee for purchasing dress
125 发包委托设计承担合容外工作服务行签订协议支付费
125 Additional agreement for any other service which Employer entrusts Designer to provide however out of the scope of the Contract shall be signed and the payment shall be paid correspondingly
126 抗力素致合法履行时双方应时协商解决
126 For any failure to perform any term or condition of this Contract due to the force majeure both parties shall in good faith attempt to settle amicably and by mutual agreement
127 合双方签字盖章生效式四 份发包 二 份设计 二 份
127 The Contract is effective once after both parties stamped and signed There are totally four copies of the Contract Employer retains two copies and Designer retains two copies
128 合生效规定应项目省级建设行政部门规定审查部门备案双方认必时 工商行政理部门签证双方履行完合规定义务合行终止
128 Once this Contract became effective it should be registered in the Auditing Section stipulated by Provincial Administrative Ministry of Construction where the Project locates Where is necessity mutually agreed by both parties the Contract shall be certified by Local Administration for Industry and Commerce This Contract is to be concluded once after both parties fulfilled their own responsibilities
129 双方认定传真电报会议纪等均合组成部分合具等法律效力
129 Any correspondence including faxes telegram meeting minutes agreed by both parties are components of the Contract which shall have the same validity with this Contract
1210 未事宜双方协商致签订补充协议补充协议合具等效力
1210 As for matters not covered in this Agreement supplementary agreement may be concluded by the Parties separately and such supplementary agreement shall have the same legal validity with this Contract
发包名称： 设计名称：
Name of the Employer Name of the Designer
(盖章）(Stamp) （盖章）(Stamp)
法定代表：（签字） 法定代表：（签字）
Legal representative Legal representative
(signature) (signature)
委托代表：（签字） 委托代表：（签字）
Authorized proxy Authorized proxy
(signature) (signature)
项目理：（签字） 项目理：（签字）
Project manager(signature) Project manager(signature)
住 ： 住 ：
Address Address
邮政编码： 邮政编码：
Postal code Postal code
电 话： 电 话：
Tel Tel
传 真： 传 真：
Fax Fax
开户银行： 开户银行
Bank Bank
银行帐号： 银行帐号：
Bank account Bank account
单位名称：
Company’s name
建设行政部门备案： 签证意见：
Record at the competent Verification opinion
Construction administration
department
（盖章） （盖章）
(Stamp) (Stamp)
备 案 号： 办 ：
Record No Handling person
备案日期： 年 月 日 签证日期： 年 月 日
Date of record Date of verification
文档香网(httpswwwxiangdangnet)户传
《香当网》用户分享的内容，不代表《香当网》观点或立场，请自行判断内容的真实性和可靠性！
该内容是文档的文本内容，更好的格式请下载文档
建设工程设计合（二）
Engineering Service Contract (Ⅱ)
（专业建设工程设计合）
(Professional Engineering Service Contract For Construction Project)
工 程 名 称：
Name of the project
工 程 点：
Location of the project
合 编 号：
（设计编填）
Contract No
(Filled in by the Designer)
设计证书等级：
Level of the design certificate
发 包 ：
Employer
设 计 ：
Designer
签 定 日 期：
Date of contract
监制
江 苏 省 建 设 厅
江苏省工商行政理局
Supervised by Jiangsu Provincial Department of Construction
Jiangsu Provincial Administration for Industry and Commerce
发包
Employer (Party A)
设计
Designer (Party B)
发包委托设计承担 工程设计工程点 双方协商致签订合执行
The Employer entrust the Designer to undertake the engineering design of *** and the location for the project is within the plant of After friendly consultation the Parties hereby sign this Contract as follows：
第条 合签订
Article 1 Basis for the conclusion of this Contract
11中华民国合法中华民国建筑法 建设工程勘察设计市场理规定
11 The Contract Law of the People’s Republic of China The Construction Law of the People’s Republic of China Regulations on the Administration of the Market for Survey and Design of Engineering Construction
12 国家方关建设工程勘察设计理法规规章
12 National and local rules and regulations on the administration of the market for survey and design of engineering construction
13建设工程批准文件
1．3 Approval documents of the engineering construction
第二条 设计
Article 2 Basis for design of the engineering construction
21发包设计委托书设计中标文件
21 Letter of Authority or documents on letter of acceptance provided by the Employer to the Designer
22发包提交基础资料
22 Basic materials submitted by the Employer
23设计采技术标准：
国家方现行技术标准规范
23 The main technological standards adopted by the Designer are as follows
Current national and local technological standards rules and regulations
第三条 合文件优先次序
Article 3 Priority of the contractual documents
Current national and local technological standards rules and regulations
构成合文件视互相说明果合文件存歧义致根优先次序判断：
The several documents forming the Contract are to be taken as mutually explanatory of one another but in case of ambiguities or discrepancies the priority of the documents forming the contract shall be as follows
31合书
31 The Contract
32中标函（文件）
32 The Letter of Acceptance (documents)
33发包求委托书
33 Requirements of the Employer and letter of authority
34投标书
34 The Tender
第四条 合项目名称规模阶段投资设计容（根行业特点填写）
Article 4 Name size stages investment and content of design (which may be filled in according to the characteristics of the industry)
名称：
Name
规模：
Size
阶段：
Stage
投资：约 万美元
Investment About dollars
设计容工作范围：
Design content and work scope：
第五条 发包设计提交关资料文件时间
Article 5 Materials and documents delivered by the Employer to the Designer and time for delivery of materials and documents
1级部门批复文件(合生效)
1Official reply document by higher authority(after effectiveness of contract)
2设计开始前应提供关技术规格资料(合生效)
2The Employer should supply related technological specification documents before starting to design
3部门方案设计审批意见（施工图开始前提供）
3 Official reply of the power supply department on consent of the power supply(supply before construction drawing)
第六条 设计发包交付设计文件份数点时间
Article 6 Delivery of design documents by the Designer to the contract issuing party and copies location and time for the delivery
第七条 费
Article 7 Charges
7 1 双方商定合设计费 万元收费计算方法国家方关规定执行国家方没规定双方商定
71 The Parties agree that charges for the design hereunder shall be The basis for charges and the method of computing shall be in accordance with relevant national
and local provisions Where there are no relevant national and local provisions it shall be discussed and determined by the Parties
7 2 果述费估算设计费双方初步设计审批批准初步设计概算核算设计费工程建设期间遇概算调整设计费应作相应调整
72 If the design charges mentioned above are appraised prices both parties will compute design charges based on the approved rough estimate of preliminary design after preliminary design approval If there is rough estimate adjustment in period of engineering construction the design price will be adjusted accordingly
第八条 支付方式
Article 8 Terms of payment
81 合生效三天发包支付设计费总额30计 万元作定金（合结算时定金抵作设计费）
81 Within three days upon the effectiveness of this contract the Employer shall pay the Designer 30 of contract price namely RMB Yuan as the down payment( The down payment shall be counted as the charges for design upon settlement of the contract)
82设计提交 方案 设计文件三天发包支付设计费总额20计 万元设计提交 施工图 设计文件三天发包支付设计费总额45计 万元工程完工结清设计费留尾款
82 Within three days upon the submission of schematic design documents by the Designer the Employer will pay 20 of contract price namely RMB Yuan Within three days upon the submission of construction drawings by the Designer the Employer will pay 45 of contract price namely RMB Yuan After completion of the project the Employer will pay the rest RMB ** *Yuan without any remainder
83 双方委托银行代付代收关费
83 The Parties shall entrust bank to collect and pay for relevant charges
第九条 双方责
Article 9 Responsibilities of the Parties
91 发包责
91 Responsibilities of the Employer
911发包合第五条规定容规定时间设计提交基础资料文件完整性正确性时限负责发包求设计违反国家关标准进行设计
发包提交述资料文件超规定期限15天设计合第六条规定交付设计文件时间延发包交付述资料文件超规定期限15天时设计权重新确定提交设计文件时间
911 The Employer shall submit to Designer basic materials and documents within specified period as provided in Article 5 of this contract and shall be responsible for the completeness accuracy and time limit of the materials and documents The Employer shall not require the Designer to conduct design in violation of relevant
national standards
In case there is a delay of less than 15 days exceeding the specified time limit for the delivery of the above materials and documents by the Employer the time limit for the Designer to deliver design documents shall be extended accordingly in case there is a delay of more than 15 days exceeding the specified time limit for the delivery of the above materials and documents by the Employer the Designer shall have the right to redetermine the time for delivery of the design documents
912 发包变更委托设计项目规模条件提交资料错误提交资料作较修改设计周期变化致造成设计设计返工工作量加时双方行协商签订补充协议（订合）重新明确关条款外发包应设计耗工作量设计支付返工费
未签订合前发包已意设计发包做项设计工作发包应支付相应设计费
912 In case of the Designer’s rework on the design resulted for changes of the engineering size and conditions of the design by the Employer or mistakes of the materials submitted or major revision on the submitted materials the Parties shall conclude supplementary agreement separately (or conclude additional agreement) and redefine relevant terms and conditions and the Employer should pay charges for rework to the Designer according to the workload
The Employer has agreed before the conclusion of the contract that it will pay charges of design to the Designer for all the design works conducted by the Designer
913 合履行期间发包求终止解合设计未开始设计工作退发包已付定金已开始设计工作发包应根设计已进行实际工作量足半时该阶段设计费半支付超半时该阶段设计费全部支付
913 During the performance of the contract if the Employer requires to terminate or cancel the contract before the Designer starts the design work the Designer will not return the down payment already paid by the Employer if the Designer has started the design work the Employer shall pay for the actual workload already done by the Designer When the actual workload of the design is less than half of the work at the stage the Employer shall pay half of the payment for the design work at the stage When the actual workload of the design is more than half of the work at the stage the Employer shall pay all the payment for the design work at the stage
914发包必须合规定支付定金收定金作设计开工标志未收定金设计权推迟设计工作开工时间交付文件时间延
914 The Employer should pay down payment as provided by the contract and receipt of down payment will be the symbol for the commencement of the design work by the Designer The Designer shall have the right to put off the commencement date of the design work if it has not received the down payment and the time for delivery shall be extended accordingly
915发包应合规定金额日期设计支付设计费逾期支付天应承担支付金额千分二逾期违约金设计提交设计文件时间延逾期超30天时设计权暂停履行阶段工作书面通知发包发包级设计审批部门设计文件审批合项目停缓建 发包均应支付应付设计费
915 The Employer should pay charges for design to the Designer at the amount and date provided in this Contract For each day of overdue payment 2‰ of the overdue payment shall be paid as damages for overdue payment and the time for delivery by the Designer shall be extended accordingly Where the delay of payment has exceeded 30 days the Designer shall have the right to suspend the performance of the work at the next stage and give written notice to the Employer In case the higher authority or competent department of design approval would not approve the design documents or the engineering construction of this contract is suspended or stopped the Employer should pay the payable charges for design
916发包求设计合规定时间提前交付设计文件时须征设计意严重背离合理设计周期发包应支付赶工费
916 If the Employer requires the Designer to deliver the design documents in advance it should get the prior consent of the Designer without serious deviation from the reasonable design circle and the Employer shall pay the crush cost
917发包应设计派驻现场工作员提供工作生活交通等方面便利条件必劳动保护装备
917 The Employer should offer conveniences in aspects of working living and traffic and necessary laborprotection equipments
918设计文件中选国家标准图部标准图方标准图发包负责解决
918 The Employer shall be responsible for the national standard drawing ministerial standard drawing and local standard drawings
919承担项目外国专家设计办公室工作接费（包括传真电话复印办公等费）
919 The Employer shall bear the expenses for receiving foreign expert in charge of the engineering to the Designer’s office (including expenses on fax telephone and office affairs)
92 设计责
92 Designer’s responsibilities
921 设计应国家规定合约定技术规范标准进行设计合第六条规定容时间份数发包交付设计文件（出现911912914915规定关交付设计文件延情况外）提交设计文件质量负责
921 The Designer should carry out design work in accordance with technological rules and standards provided in this contract or the state and deliver design documents as the content time and copies specified in Article 6 of this Contract (except for the circumstances provided in Art 911 912 914 915 under which the delivery of design documents may be extended) and shall be responsible for the quality of the design documents
922 设计合理年限体结构50年（砖混框架结构）
922 The design life of the engineering construction shall be main structure fifty years
923负责外商设计资料进行审查负责该合项目设计联络工作
923 The Designer shall be responsible for the scrutiny on the foreign investor’s design material and contact on the design of the engineering
924 设计设计文件出现遗漏错误负责修改补充设计设计错误造成工程质量事损失设计负责采取补救措施外应免收损失部分设计费根损失程度发包支付赔偿金赔偿金数额受损部分设计费相等
924 The Designer shall be responsible for the revision or supplement to the mistakes or omission of the design documents If any engineering quality accidents happen because of the Designer’s fault the Designer should be responsible for taking remedial measures as well as reduce the design charges on the affected part of the design work and compensate the Employer according to the degree of loss The amount of the damages for compensation is no more than the design price of the actual loss
925 设计原延误设计文件交付时间延误天应减收该项目应收设计费千分二
925 If the delivery of design documents are delayed for the Designer’s reason each day overdue will resulted in the reduction of 2‰ of the design charges for the engineering
926 合生效设计求终止解合设计应双倍返发包已支付定金
926 After the contract enters into force the Designer may require termination or cancellation of the contract and the Designer should return the down payment in double
927 设计交付设计文件规定参加关级设计审查根审查结负责超出原定范围容做必调查补充设计合规定时限交付设计文件年项目开始施工负责发包施工单位进行设计交底处理关设计问题参加竣工验收年项目尚未开始施工
设计负责述工作需工作量发包适收取咨询服务费收费额双方商定
927 Upon delivery of the design documents the Designer shall participate in the inspection on the design by the relevant higher authority as provide and shall be responsible for necessary adjustment and supplements to the content within the original scope of the design according to the inspection conclusion The Designer shall start the construction within one year upon delivery of the design documents within the specified time limit and shall be responsible for the technological disclosure to the Employer and construction unit handling with relevant matters on design and participation in the acceptance upon completion of the engineering construction In case the engineering construction has not started within one year the Designer shall still be responsible for the above work and may collect reasonable service fee for consultancy from the Employer according to the needed workload The amount of the service fee shall be discussed and determined by the Parties
第十条 保密
Article 10 Confidentiality
双方均应保护方知识产权未方意方均方资料文件擅修改复制第三转合项目外项目发生情况泄密方承担切引起果承担赔偿责
Both Parties shall protect each other’s intellectual property rights Without prior consent neither party shall revise copy or transfer to a third party or use for the project other than the project of this Contract any materials and documents of the other party Under such circumstances the disclosing party shall be responsible for all the any consequence it resulted and shall bear the relevant compensation
第十条 仲裁
Article 11 Arbitration
建设工程设计合发生争议发包设计应时协商解决建设行政部门调解调解成时双方事意 仲裁委员会仲裁双方事未合中约定仲裁机构事未达成仲裁书面协议民法院起诉
If any disputes arises in connection with this Engineering Service Contract it shall be settle by friendly consultation of the Parties or be submitted to the competent local construction administration department for mediation Where the dispute can not be settled by mediation it shall be submitted to the Arbitration Committee for settlement Where the Parties have not agreed on the arbitration organization in the Contract nor conclude arbitration agreement in written form the dispute will be brought to the People’s Court
第十二条 合生效
Article 12 Contract effective and miscellaneous
121 发包求设计派专长期驻施工现场进行配合解决关问题时双方应行签定技术咨询服务合
121 As per the request of the Employer for dispatch of personnel to stay on the Construction site so as to coordinate and solve relevant issues the individual technical consultant service contract shall be signed by both parties
122 设计合项目服务施工安装结束止
122 Service provided by the Designer for the Project in this Contract will be concluded until the completion of construction and installation
123工程项目中设计指定建筑材料设备生产厂供货商发包需设计配合建筑材料设备加工订货时需费发包承担
123 In the projects of the Contract Designer shall not appoint manufacturers or Designers of construction materials and equipments Where there is a necessity that Designer shall cooperate with Employer in ordering the process of construction materials and equipments the relevant fee shall be paid by Employer
124 发包委托设计配合引进项目设计务询价外谈判国外技术考察直建成投产阶段应吸收承担关设计务设计员参加出国费制服费外费发包支付
124 The Employer entrusted the Designer to cooperate with the engineering work of imported project and design personnel undertaking relevant design assignment shall be included in all stages from enquiry business negotiation domestic and overseas technical inspection until the production period The fee for overseas business trip and other relevant fee will be paid by Employer except the fee for purchasing dress
125 发包委托设计承担合容外工作服务行签订协议支付费
125 Additional agreement for any other service which Employer entrusts Designer to provide however out of the scope of the Contract shall be signed and the payment shall be paid correspondingly
126 抗力素致合法履行时双方应时协商解决
126 For any failure to perform any term or condition of this Contract due to the force majeure both parties shall in good faith attempt to settle amicably and by mutual agreement
127 合双方签字盖章生效式四 份发包 二 份设计 二 份
127 The Contract is effective once after both parties stamped and signed There are totally four copies of the Contract Employer retains two copies and Designer retains two copies
128 合生效规定应项目省级建设行政部门规定审查部门备案双方认必时 工商行政理部门签证双方履行完合规定义务合行终止
128 Once this Contract became effective it should be registered in the Auditing Section stipulated by Provincial Administrative Ministry of Construction where the Project locates Where is necessity mutually agreed by both parties the Contract shall be certified by Local Administration for Industry and Commerce This Contract is to be concluded once after both parties fulfilled their own responsibilities
129 双方认定传真电报会议纪等均合组成部分合具等法律效力
129 Any correspondence including faxes telegram meeting minutes agreed by both parties are components of the Contract which shall have the same validity with this Contract
1210 未事宜双方协商致签订补充协议补充协议合具等效力
1210 As for matters not covered in this Agreement supplementary agreement may be concluded by the Parties separately and such supplementary agreement shall have the same legal validity with this Contract
发包名称： 设计名称：
Name of the Employer Name of the Designer
(盖章）(Stamp) （盖章）(Stamp)
法定代表：（签字） 法定代表：（签字）
Legal representative Legal representative
(signature) (signature)
委托代表：（签字） 委托代表：（签字）
Authorized proxy Authorized proxy
(signature) (signature)
项目理：（签字） 项目理：（签字）
Project manager(signature) Project manager(signature)
住 ： 住 ：
Address Address
邮政编码： 邮政编码：
Postal code Postal code
电 话： 电 话：
Tel Tel
传 真： 传 真：
Fax Fax
开户银行： 开户银行
Bank Bank
银行帐号： 银行帐号：
Bank account Bank account
单位名称：
Company’s name
建设行政部门备案： 签证意见：
Record at the competent Verification opinion
Construction administration
department
（盖章） （盖章）
(Stamp) (Stamp)
备 案 号： 办 ：
Record No Handling person
备案日期： 年 月 日 签证日期： 年 月 日
Date of record Date of verification
文档香网(httpswwwxiangdangnet)户传
《香当网》用户分享的内容，不代表《香当网》观点或立场，请自行判断内容的真实性和可靠性！
该内容是文档的文本内容，更好的格式请下载文档